Terms of Service

1. ACCEPTANCE OF TERMS

By accessing our website or engaging our construction services, you agree to these Terms of Service. If you do not agree, please discontinue use of our services.

2. COMPANY INFORMATION

Arista’s Construction, Inc.
License: California Contractors License #1117672
Address: 7100 Hayvenhurst Ave P “B”, Lake Balboa, CA 91406

3. SERVICES PROVIDED

We provide general construction services including but not limited to:

Residential and commercial construction
Remodeling and renovation services
Project consultation and planning
Construction management services

4. ESTIMATES AND CONTRACTS

4.1 Estimates

Estimates are provided free of charge and are valid for 30 days
Estimates are based on information provided and site conditions at time of inspection
Final costs may vary based on actual conditions and change orders

4.2 Contracts

All work requires a signed written contract
Contracts specify scope of work, materials, timeline, and payment terms
Changes to contracted work require written change orders

5. PAYMENT TERMS

5.1 Payment Schedule

Payment schedules are outlined in individual contracts
Progress payments are typically required at project milestones
Final payment is due upon satisfactory completion

5.2 Late Payments

Late payments may incur interest charges as specified in contracts
We reserve the right to suspend work for overdue payments
Legal action may be taken for significantly overdue accounts

6. WARRANTIES AND GUARANTEES

6.1 Workmanship Warranty

We provide a one-year warranty on workmanship from completion date
Warranty covers defects in our work, excluding normal wear and tear
Warranty is void if modifications are made by others

6.2 Materials

Material warranties are provided by manufacturers
We assist in warranty claims but are not responsible for manufacturer defects

7. LIMITATIONS OF LIABILITY

7.1 Scope of Liability

Our liability is limited to:

Direct damages related to our workmanship
The total contract amount for the specific project
We are not liable for consequential, indirect, or punitive damages

7.2 Force Majeure

We are not liable for delays or inability to perform due to:

Weather conditions
Government regulations or permit delays
Material shortages or supply chain issues
Acts of God or other circumstances beyond our control

8. INSURANCE AND LICENSING

We maintain current California Contractors License #1117672
We carry general liability and workers’ compensation insurance
Certificates of insurance are available upon request
We are bonded as required by California law

9. DISPUTE RESOLUTION

9.1 Initial Resolution

We encourage direct communication to resolve any concerns or disputes.

9.2 Mediation and Arbitration

Disputes may be subject to mediation or arbitration as specified in contracts
California law governs all agreements and disputes
Venue for legal proceedings is Los Angeles County, California

10. INTELLECTUAL PROPERTY

Project plans and designs remain our property unless otherwise specified
Customers receive limited use rights for their specific project
We reserve the right to use project photos for marketing purposes

11. WEBSITE TERMS

11.1 Acceptable Use

Website is for informational purposes and business inquiries
Users must not misuse or attempt to harm our website
Content is for personal, non-commercial use unless otherwise specified

11.2 Third-Party Links

Our website may contain links to third-party sites
We are not responsible for third-party content or policies

12. MODIFICATIONS

We reserve the right to modify these terms at any time. Changes will be posted on our website with an updated effective date.

13. SEVERABILITY

If any provision of these terms is found unenforceable, the remaining provisions remain in full effect.

14. CONTACT INFORMATION

For questions about these terms or our services:

Arista’s Construction, Inc.
7100 Hayvenhurst Ave P “B”
Lake Balboa, CA 91406
Phone: 323.330.7131
Email: info@aristasconstruction.com
License: #1117672

DISCLAIMER: This document provides general terms and policies. Specific project terms are governed by individual construction contracts. We recommend consulting with legal counsel for complex projects or disputes.